Question Details

[answered] 13 1671 Dormitory Authority v. Continental Casualty UNITED

Anyone can give me a case brief of this case? (citation, facts, issues, decision and reason) Thank you very much!

13 1671


Dormitory Authority v. Continental Casualty UNITED STATES COURT OF APPEALS




August Term, 2013 1












































23 (Argued: March 12, 2014 Decided: June 23, 2014) Docket No. 13 1671 (L), 13 1700 (xap)








Plaintiff Appellee Cross










Defendant Appellant Cross




x JACOBS, POOLER, Circuit Judges, Rom?n, District Judge.* 1




3 Before: 4 the insurer of the architectural firm that designed it, the insurer appeals from the 5 judgment of the United States District Court for the Southern District of New 6 York (Forrest, J.), ruling, on summary judgment, that two design flaws in the 7 same structure were not ?related.? Under the terms of a stipulation between the 8 parties, a separate limit of liability was therefore available to fix each flaw. The 9 building owner cross appeals the calculation of prejudgment interest. We affirm 10 In this declaratory judgment action between the owner of a building and as to the declaration and vacate as to interest. 11


























24 RICHARD SIMPSON (Gary P. Seligman


and Leland H. Jones IV, on the brief), Wiley


Rein LLP, Washington, DC, for


Appellant Cross Appellee.




Shapiro, Frederick D. Page, Timothy B.


Froessel, on the brief), Holland & Knight


LLP, Washington, DC, for


Appellee Cross Appellant. * The Honorable Nelson S. Rom?n, United States District Judge for the


Southern District of New York, sitting by designation.


2 1


2 DENNIS JACOBS, Circuit Judge:


Continental Casualty Company issued claims made liability policies to the 3 architectural firm responsible for designing and overseeing the construction of a 4 building for the Dormitory Authority of the State of New York (?DASNY?). In 5 this declaratory judgment action, the insurer appeals from a judgment of the 6 United States District Court for the Southern District of New York (Forrest, J.), 7 ruling on summary judgment that the two design flaws in the same structure 8 were not ?related.? The parties had stipulated that if the two flaws were held to 9 be unrelated, the insurer would indemnify loss caused by the second flaw with a 10


11 second limit of liability.


Continental appeals from the declaration, and further argues against the 12 imposition of prejudgment interest. DASNY?s cross appeal argues that the 13 district court should have calculated prejudgment interest at New York?s 14 statutory rate of nine percent. We affirm as to the declaration and vacate as to the 15 calculation of interest. 16


17 BACKGROUND 18 In September 1995, DASNY contracted with an architectural firm (the 19 ?Architects?) to design and oversee the construction of a new building for Baruch


3 1 College of the City University of New York. Construction, begun in 1997, was 2 beset by delays from the outset. Plans drawn by the architects and its 3 subcontractor erred in their estimate of the steel requirement and in the 4 specifications of the structural steel girts and exterior facade (the ?Steel Girt 5 Tolerance Issue?). To recover losses from the resulting delay and expense, 6 DASNY sent a demand letter to the Architects detailing the Steel Girt Tolerance 7 Issue in May 2002 (the ?2002 Demand Letter?). 8


9 After the Project was finished in 2001, it was discovered that excessive


accumulations of snow and ice were sliding off the building onto sidewalks a 10 considerable distance away. In the winter of 2003 04, the architects commissioned 11 a subcontractor to study the ?Ice Control Issue.? The study concluded that the 12 design of the facade failed to account for temperature variations appropriate for a 13 building in New York, and that the problem could not be solved by adding 14 canopies, as had been hoped. Study of the problem continued into 2005. 15 In June 2004, Travelers Casualty & Surety Company (?Travelers?), the 16 surety on performance bonds purchased by the Project?s general contractor, sued 17 DASNY and the Architects. DASNY was sued for delay related expense and for 18 pass through claims from subcontractors, and the Architects were sued for 19 contributing to the delays and for breach of professional duties.


4 1 DASNY cross claimed against the Architects, generally alleging breach of 2 contract and negligence. In 2005, DASNY responded to an interrogatory seeking a 3 specification of claims; its answer identified the Ice Control Issue for the first time 4 in the litigation. 5 The Architects? professional liability policies were claims made policies: 6 coverage was triggered by a claim made against the Architects during the policy 7 period. Two policies were thereby implicated: 2000 02 and 2003 04. The contracts 8 provided, however, that ?[a]ll related claims shall be considered a single claim 9 first made and reported . . . within the Policy year in which the earliest of the 10 related claims was first made and reported[.]? J.A. at 796. ?Related claims? were 11 defined as ?all claims made against [the Architects] and reported to [Continental] 12 during any policy year arising out of . . . a single wrongful act or related wrongful 13 acts[.]? Id. at 793. 14 In 2009, DASNY, the Architects, and Continental agreed to settle DASNY?s 15 cross claim against the Architects in the Travelers suit: Continental would pay 16 DASNY (and has) approximately $3.1 million under the 2000 02 policy for the 17 claim made in the 2002 Demand Letter, i.e. the Steel Girt Tolerance Issue. 18 Continental would pay an additional $3 million under the 2003 04 policy if 19 DASNY succeeded in obtaining a declaratory judgment that the Ice Control Issue


5 1 did not ?arise out of the same or related wrongful acts identified in the [2002 2 Demand Letter].? J.A. at 250 51. To that end, DASNY commenced this 3 declaratory judgment action in January 2013. 4 In March 2013, the district court ruled, on summary judgment, that the Ice 5 Control Issue was not ?related? to the Steel Girt Tolerance Issue, and therefore 6 entered judgment ordering Continental to pay $3 million pursuant to the 7 settlement agreement. The district court awarded prejudgment interest calculated 8 on the basis of the average prime interest rate of 3.25% (totaling $389,732.88), and 9 rejected DASNY?s argument that a statutory interest rate of nine percent applied 10


11 pursuant to N.Y.C.P.L.R. ?? 5001, 5004.


Continental appeals the district court?s declaration that the Ice Control Issue 12 is not ?related? to the wrongful acts identified in the 2002 Demand Letter, and 13 from the imposition of prejudgment interest. DASNY cross appeals the rejection 14 of the nine percent statutory interest rate, see N.Y.C.P.L.R. ?? 5001, 5004. 15


16 I 17 We review the grant of a motion for summary judgment de novo. Guippone 18 v. BH S&B Holdings LLC, 737 F.3d 221, 225 (2d Cir. 2013). ?[S]ummary judgment 19 is proper ?if . . . there is no genuine issue as to any material fact and the moving


6 1 party is entitled to a judgment as a matter of law.?? Celotex v. Catrett, 477 U.S. 2 317, 322 (1986) (quoting Fed. R. Civ. P. 56(c)). 3 Continental presents two arguments on the relatedness question: A) the 4 wording of the 2002 Demand letter encompasses both the Steel Girt Tolerance 5 Issue and the Ice Control Issue; and B) the two issues are ?related claims? as that 6 phrase is defined in the insurance policies. 7




9 A


Continental points out that the 2002 Demand Letter alleges professional 10 negligence in terms broad enough to include all design defects in the building: the 11 Steel Girt Tolerance Issue as well as the Ice Control Issue. The letter opens with 12 two categorical allegations: the failure to complete design services in a timely 13 fashion and the failure to properly coordinate services with other members of the 14 design team. However, the rest of the letter specifies the Architects? failures 15 concerning the Steel Girt Tolerance Issue, and identifies no other failure of design 16 or execution. 17


18 By 2002, DASNY was already aware of the Ice Control Issue, but the


Architects were proposing additional canopies, a fix that would be easy and 19


7 1 cheap. It was not until after the study conducted in the winter of 2003 04 that it 2 became clear that major design changes would be needed. 3 The 2002 Demand Letter, issued before the 2003 04 study, cannot be fairly 4 read to concern the Ice Control Issue; and, focused as it is entirely on the Steel Girt 5 Tolerance Issue, it cannot be fairly read as an omnibus claim concerning all 6 architectural defects in the Baruch College building. 7


8 B 9 Continental also argues that the Steel Girt Tolerance Issue and the Ice 10 Control Issue are ?related claims? under the policy wording because they ?arise 11 out of a single wrongful act or related wrongful acts.? J.A. at 793. We agree with 12 the district court that the Steel Girt Tolerance Issue and the Ice Control Issue arise 13 from two unrelated wrongful acts. One has to do with the structural integrity of 14 the building; the other, with its aesthetic design. The issues inhere in different 15 systems, each with its own distinct engineering considerations. The two issues 16 involved different design teams; two separate sets of contractors worked on them. 17 The problems ultimately manifested themselves at different times and resulted in 18 different types of damage. The solutions to each issue were wholly different. 19


8 1 That both may have resulted from the generalized negligence of the Architects is 2 an insufficient degree of relatedness. 3


4 II 5 New York law mandates the imposition of prejudgment interest at the rate 6 of nine percent under certain circumstances. See N.Y.C.P.L.R. ?? 5001, 5004. We 7 review de novo the district court?s decision that N.Y.C.P.L.R. ? 5001 does not apply. 8 See Salve Regina Coll. v. Russel, 499 U.S. 225, 231 (1991). If N.Y.C.P.L.R. ? 5001 9 does not apply, we review the assessment of prejudgment interest for abuse of 10 discretion. Fed. Ins. Co. v. Am. Home Assur. Co., 639 F.3d 557, 566 (2d Cir. 2011). 11 New York?s statutory rate applies to ?a sum awarded because of a breach of 12 performance of a contract, or because of an act or omission depriving or otherwise 13 interfering with title to, or possession or enjoyment of, property.? N.Y.C.P.L.R. ? 14 5001. This declaratory judgment action did not arise out of the breach of a 15 contract or the deprivation of property. The coverage issue was compromised in a 16 way that left unsettled a number of defenses potentially available to the insurer. 17 DASNY sued under the settlement agreement, which conditioned Continental?s 18 obligation to pay upon DASNY?s success in this suit. Since DASNY?s entitlement 19


9 1 to the $3 million did not arise until the declaratory judgment was rendered, the 2 nine percent statutory rate is not applicable. 3 For much the same reason, the district court abused its discretion by 4 awarding prejudgment interest from the date of the settlement agreement itself. 5 Interest does not start accruing until there is an obligation to pay. See In re Rio 6 Grande Transp., Inc., 770 F.2d 262, 264 (2d Cir. 1985). The obligation to pay under 7 the settlement agreement was not triggered until the district court entered a 8 judgment for DASNY on the relatedness issue. Therefore, the award of 9 prejudgment interest was improper. We express no opinion as to post judgment 10 interest. 11


12 CONCLUSION 13 For the foregoing reasons, we affirm the declaration that the two issues are 14 unrelated, vacate the award of prejudgment interest, and remand for any further 15 proceedings that may be required to enter judgment. 16 10


Solution details:

This question was answered on: Sep 18, 2020

PRICE: $15 (25.37 KB)

Buy this answer for only: $15

This attachment is locked

We have a ready expert answer for this paper which you can use for in-depth understanding, research editing or paraphrasing. You can buy it or order for a fresh, original and plagiarism-free copy from our tutoring website (Deadline assured. Flexible pricing. TurnItIn Report provided)

Pay using PayPal (No PayPal account Required) or your credit card . All your purchases are securely protected by .

About this Question






Sep 18, 2020





We have top-notch tutors who can do your essay/homework for you at a reasonable cost and then you can simply use that essay as a template to build your own arguments.

You can also use these solutions:

  • As a reference for in-depth understanding of the subject.
  • As a source of ideas / reasoning for your own research (if properly referenced)
  • For editing and paraphrasing (check your institution's definition of plagiarism and recommended paraphrase).
This we believe is a better way of understanding a problem and makes use of the efficiency of time of the student.


Order New Solution. Quick Turnaround

Click on the button below in order to Order for a New, Original and High-Quality Essay Solutions. New orders are original solutions and precise to your writing instruction requirements. Place a New Order using the button below.


Order Now